yourstate.us
Home / Texas / Transportation Code
Tex. Transportation Code § 315.095

SUSPENSION OF WORK

Texas · Texas Transportation Code · Status: effective

Get this as JSONEmbed this
Cite this
Citation
Tex. Transportation Code § 315.095, SUSPENSION OF WORK, Texas, version 1 as recorded 2026-07-09, yourstate.us, https://yourstate.us/provision/569755
Permanent ID
ys:prov:569755@1
SHA-256
151f6f034376fab6cd6e839fd1fc3b572db209bd19f8bd16249ee6327118a7c0

The hash is SHA-256 of this version's text, with every run of whitespace collapsed to a single space and the ends trimmed. The ID always leads back here, and checking it says whether the text you cited is still the current version.

Full text

When suit is brought under Section 315.092, the municipality or the contractor may suspend performance of work until a final judgment is rendered in the case and all appellate remedies are exhausted.