18 CFR 1308.24
§ 1308.24 Undue delay in Contracting Officer's decision.
United States · 18 CFR — Conservation of Power and Water Resources · Status: effective
Cite this
- Citation
- 18 CFR 1308.24, § 1308.24 Undue delay in Contracting Officer's decision, United States, version 1 as recorded 2026-07-09, yourstate.us, https://yourstate.us/provision/72526
- Permanent ID
ys:prov:72526@1- SHA-256
f975aa616961f0141471de72a527793a3039edac67aa54934ec896174012236b
The hash is SHA-256 of this version's text, with every run of whitespace collapsed to a single space and the ends trimmed. The ID always leads back here, and checking it says whether the text you cited is still the current version.
Full text
(a) If there is an undue delay by a Contracting Officer in issuing a decision on a claim, the Contractor may request the Chairman to direct the Contracting Officer to issue a decision within a specified period of time.
(b) A request under this section shall:
(1) Be in writing;
(2) State the date on which the claim was submitted to the Contracting Officer.
(3) State the date suggested for issuance of a decision by the Contracting Officer.
(c) TVA may reply to a motion under this section within 5 days after its receipt.
(d) The Chairman shall issue a written decision on the request. If granted, the decision shall specify the date by which the Contracting Officer's decision is to be rendered, and a copy shall be served on the Contracting Officer.
Legislative history
This is a federal regulation, adopted through agency rulemaking under the Administrative Procedure Act — not enacted by a recorded vote of Congress.