Cal. Public Contract Code § 7102
Cal. Public Contract Code § 7102
California · California Public Contract Code · Status: effective
Cite this
- Citation
- Cal. Public Contract Code § 7102, California, version 1 as recorded 2026-07-25, yourstate.us, https://yourstate.us/provision/896200
- Permanent ID
ys:prov:896200@1- SHA-256
0a9d75be8e4877132f7633f089114ea2ff1eb1d2e00b3c57133cc16767f67b2f
The hash is SHA-256 of this version's text, with every run of whitespace collapsed to a single space and the ends trimmed. The ID always leads back here, and checking it says whether the text you cited is still the current version.
Full text
Contract provisions in construction contracts of public agencies and subcontracts thereunder which limit the contractee’s liability to an extension of time for delay for which the contractee is responsible and which delay is unreasonable under the circumstances involved, and not within the contemplation of the parties, shall not be construed to preclude the recovery of damages by the contractor or subcontractor.
No public agency may require the waiver, alteration, or limitation of the applicability of this section. Any such waiver, alteration, or limitation is void. This section shall not be construed to void any provision in a construction contract which requires notice of delays, provides for arbitration or other procedure for settlement, or provides for liquidated damages.